Effective Date: May 20, 2025
Welcome to RUVA Promoters. These Terms and Conditions (“Terms”) govern your access to and use of our website, services, and any interactions you may have with us online or offline. By using this website or engaging with our team, you agree to be bound by these Terms.
RUVA Promoters is a real estate development firm based in Chennai, operating under the Ramkumar Group of Companies. We offer residential and commercial projects across Tamil Nadu.
This website is for informational purposes only. Project details, specifications, availability, and pricing are subject to change without notice.
The images, brochures, videos, and other content provided are indicative and for illustrative purposes only.
Actual layouts, floor plans, approvals, or amenities may vary depending on regulatory approvals, site conditions, or other factors.
No information on this website constitutes a legal offer or contract unless expressly stated in writing.
All project-related information such as floor plans, approvals, and availability is regularly updated but not guaranteed to be current at all times.
Pricing, offers, and payment plans are subject to change without prior notice.
Booking a property is subject to specific terms mentioned in the Agreement for Sale or Builder-Buyer Agreement, which will override any general claims made on the website.
We may engage or refer third-party service providers (e.g., banks, legal experts, architects, registration consultants). RUVA Promoters is not responsible for the terms, delays, or services provided by such third parties.
All content on this website — including text, images, designs, code, logos, branding, and other media — is the property of RUVA Promoters unless stated otherwise.
Some images and icons used are sourced from licensed platforms such as Freepik.com, Unsplash.com, etc., under their respective usage terms.
You may not copy, reproduce, distribute, or use any content from our website for commercial purposes without our prior written permission.
By using our website, you agree not to:
Upload or transmit any malicious code, viruses, or harmful content.
Attempt unauthorized access to systems or databases.
Use the site for fraudulent, misleading, or unlawful purposes.
RUVA Promoters will not be liable for:
Any direct or indirect damages arising from the use or inability to use this website.
Inaccuracies, delays, or errors in content, pricing, or availability.
Actions taken based on information presented on this website.
All purchases and engagements are governed solely by the respective legal agreements and government regulations applicable at the time of transaction.
These Terms are governed by the laws of India and fall under the jurisdiction of the Courts in Chennai, Tamil Nadu. Any disputes will be resolved in accordance with applicable Indian laws.
RUVA Promoters reserves the right to update or modify these Terms at any time without prior notice. Continued use of the website implies acceptance of the revised Terms.
For questions, clarifications, or grievances:
RUVA PROMOTERS is a luxury real estate firm specializing in visionary architecture, bespoke interiors, and turnkey solutions. With a commitment to excellence, we transform spaces into timeless works of art.
Copyright © 2025 – Ruva Promoters. All Rights Reserved.